Terms & Conditions – Integral Plexus Solutions

Welcome to Integral Plexus Solutions. By accessing our website, submitting enquiries, or using our services, you agree to follow the terms and conditions stated below.

1. Introduction

These terms ensure transparency and a clear understanding between Integral Plexus Solutions and our customers. If you do not agree, please refrain from using our services.

2. Company Information

Integral Plexus Solutions
Coimbatore, Tamil Nadu, India
Email: integralplexussolutions@gmail.com
Contact: 7603946546 / 9500296546

3. Services Offered

• CCTV Surveillance Systems
• Security & Alarm Systems
• Intercom & EPABX Systems
• Biometric Access & Attendance Systems
• Networking Solutions (WAN/LAN)
• Internet Services & Connectivity Setup
• Home Automation Solutions
• Home Theatre Audio Systems
• Fire Alarm Systems

All services are subject to site inspection, technical feasibility, and customer requirements.

4. Quotations & Pricing

• Quotations are valid for a limited period.
• Prices may change based on material or market conditions.
• Final pricing is confirmed after site inspection.
• Additional work beyond quotation may incur extra charges.

5. Installation & Execution

• Installation timelines depend on site readiness.
• Customers must provide access and required permissions.
• Customer-side delays may affect project timelines.

6. Payment Terms

• Advance payment may be required.
• Remaining payment must follow agreed milestones.
• Delayed payments may impact support services.

7. Warranty & Support

• Manufacturer warranty applies where applicable.
• Warranty does not cover physical damage, improper usage, voltage fluctuations, or unauthorized modifications.
• AMC support provided as per agreement.

8. Customer Responsibilities

• Provide accurate consultation information.
• Ensure safe site conditions.
• Avoid unauthorized modifications.

9. Limitation of Liability

• No liability for misuse or negligence.
• No responsibility for third-party service failures.
• No liability for indirect or consequential losses.

10. Intellectual Property

All website content including text, logos, and design elements belong to Integral Plexus Solutions and may not be reused without written permission.

11. Changes to Terms

We reserve the right to update these Terms & Conditions at any time. Updated versions will be published on this page.

12. Governing Law

These terms are governed by the laws of India. Any disputes shall fall under the jurisdiction of the courts in Coimbatore, Tamil Nadu.

13. Contact Information

For any questions regarding these terms, please contact:
integralplexussolutions@gmail.com